JBCC Contract Template fot Minor Works JBCC Minor Works Contract Doc. October 10, | Author: Sarisha Harrychund | Category: General Contractor. JBCC Minor Works Agreement. Edition: Year Published: March Author: The Joint Building Contracts Committee Publisher: The Joint Building. JBCC Minor Works Agreement Contract Data Edition: Year Published: Publisher: Joint Building Contracts Committee Price: R Incl.
|Published (Last):||13 July 2004|
|PDF File Size:||14.10 Mb|
|ePub File Size:||10.77 Mb|
|Price:||Free* [*Free Regsitration Required]|
We need your help!
Experience has shown that changes drafted by others, including members of the building professions, often have results very different from those intended which may be prejudicial to either or both parties Special Note Although this Minor Works Agreement is part of the JBCC Series documents it has been formulated for use specifically with its own supplementary documents. Where applicable such amount shall M inor W orks Agreement Page 4 include existing buildings and their contents.
The land or place on, over, under, in or through which the works is to be executed and as stated in the contract data TAX: The retention held shall include any unpaid amount due [ The principal agent shall not preselect any of the jcc available to the contractor The construction period and latent defects liability period shall commence with the handover of the site 5.
Welcome to JBCC®
The parties shall give all notices and pay all charges required by such authorities. The employer may employ others [5.
We are a non-profit group that run this website to share documents. The contractor shall report the cause and effect of such delay and the working days claimed to the principal agent at the next meeting held [6.
JBCC Minor Works Contract Doc – Free Download PDF
The contractor may dispute such reasons and the effects thereof [ Please copy and paste this embed script to where you want to embed Embed Script. If it is considered essential to make changes, users are advised that it is necessary for such changes to be drafted by qualified legal persons with extensive knowledge of the JBCC documentation and the construction industry.
The works is of a complex nature The construction period is anticipated to be more than nine months The necessary contract documentation is not complete and available at tender stage Sectional completions are required Copyright Reserved The Joint Building Contracts Committee claims authorship of this work.
Unauthorised reproduction of the work is an infringement of the copyright in the work.
A defect that a reasonable inspection of the works by the principal agent would not have revealed before the issue of the defects list LAW: Workz done and signed at on Name of signatory Capacity of signatory for and on behalf of the employer who by signature hereof warrants authorisation hereto Signed as Witness 1 Thus done and signed at Name of signatory on for and on behalf of the contractor who by signature hereof warrants authorisation hereto Capacity of signatory Signed as Witness 2 Details of Witness 1 Details of Witness 2 Name: Series documents are obtainable through most regional offices of JBCC constituents as listed on the cover of the document.
Twenty-four 24 hour days commencing at midnight Where the final payment certificate favours the employer the security shall expire when the contractor makes payment Such liability shall not exceed the insurance deductible stated in the contract data in any particular instance 4.
Should the contractor fail to submit such an analysis the principal agent shall prepare the analysis We need your help to maintenance this website. bjcc
No agreement or addendum varying, adding to, deleting or terminating this agreement including this clause shall be effective unless reduced to writing and signed by the parties The bank rate that is applicable from time to time to registered banks when borrowing money from the Central or Reserve Bank of the wprks named in the contract data.
Materials and goods delivered to the contractor for inclusion in the works stored on the site but not yet part of the works PARTY: The documentation sets out a clear, balanced and enforceable set of procedures, rights and obligations, which when competently managed and administered, protect the employer and contractor alike. The principal agent shall be informed of the name of such representative where so appointed.
The edition of the Summary Procedure Rules for the Conduct of Arbitrations, published by the Association of Arbitrators Southern Africa and current when the dispute is declared, shall apply The JBCC supplies printed documents exclusively to constituents and does not sell direct to users. M inor Wworks orks Agreement Page 16 Where applicable the principal agent shall treat such correction as an adjustment [ Failure to agree the value shall not relieve the contractor of his responsibility to comply with the contract instruction The principal agent shall deal with the amounts thus paid [ In pursuance of the objective the parties undertake to carry out their reciprocal obligations 1.
JBCC Minor Works Contract Doc
The contractor may appoint a competent representative to administer and control the works in his stead. Please fill this form, we will try to respond as soon as possible. The word or phrase of a definition is highlighted in the text and shall bear the meaning assigned to it in this 1. The principal agent shall hold a signed set of contract documents to be produced as and when required 4.
Thank woros for interesting in our services. Works also includes materials and goods and those supplied free or otherwise by the employer to the contractor and excludes work or installations to be executed by direct contractors 1.
JBCC: Joint Building Contracts Committee
Where considered necessary the principal agent shall revise the final account within ten 10 working days and resubmit such final account to the contractor Where the final hbcc Such change shall be deemed to be a contract instruction 7. The principal agent shall include such interest in the next payment certificate [ The other objectives of the JBCC are to: Either party may, at any time, by notice to the other change, its physical address provided that it is in the same country as that initially stated in the contract data minoor.
Such contract minutes shall be issued to the employer and jbfc contractor for action. Where such word or phrase is not highlighted it shall bear the meaning consistent with the context of its use.